85-25 Exhibit A- Matrix proposal for 25 Lakeside.pdf

OF UNANTICIPATED HAZARDOUS MATERIALS Hazardous materials or certain types of hazardous materials may exist at a site where there is no reason to believe they could or should be present Matrix and the CLIENT agree that the discovery of unanticipated hazardous materials constitutes a changed condition mandating a renegotiation of the scope of Services and compensation for the Services or termination of the Agreement, Matrix agrees to notify the CLIENT as soon as practically possible should unanticipated hazardous materials or suspected hazardous materials be encountered. The CLIENT authorizes Matrix to take measures that in Matrix’s professional opinion are justified or legally required to preserve and protect the health and safety of Matrix’s personnel and the public, and/or the environment, and the CLIENT agrees to compensate Matrix for the additional cost of such measures In addition, the CLIENT waives any claim against Matrix, and agrees to indemnify, defend and hold Matrix harmless from any claim or liability for injury or loss arising from Matrix’s encountering, reporting or responding to unanticipated hazardous materials or suspected hazardous materials. The CLIENT also agrees to compensate Matrix for time spent and expenses incurred by Matrix in defense of any such claim, with such compensation to be based upon Matrix's prevailing fee schedule and expense reimbursement policy. Section 9: STANDARD OF CARE The Services provided by Matrix under the Agreement will be conducted in @ manner consistent with that level of care and skill ordinarily exercised by members of the profession currently practicing in the same locality under similar conditions. No other representation, express or implied, and no ~ warranty or guarantee, in fact or by law, whether of merchantability or fitness for a particular purpose or otherwise, is included or intended in the Agreement, or in any report, opinion, document or otherwise. Matrix shall not have control over or charge of and shall not be responsible for the acts or omissions of CLIENT and/or Builder/Contractor, subcontractors, consultants or their agents or employees, or of any other persons or entities performing portions of the Work. Matrix shall not supervise, direct or have control over the contractor(s) work, nor shall Matrix have any authority over, or responsibility for, the means, methods,

es performing portions of the Work. Matrix shall not supervise, direct or have control over the contractor(s) work, nor shall Matrix have any authority over, or responsibility for, the means, methods, techniques, sequences or procedures of construction selected by the contractor(s), or for any safety precautions or programs incident to the work of the contractor(s), or for any failure of the contractor(s) in furnishing or performing its(thelr) work. Matrix neither guarantees the performance of any construction contracts by contractor(s), nor assumes responsibility or liability for the contractor's(s’) failure to furnish or perform it's (their) work in accordance with the applicable contract documents. When provided, and unless otherwise expressly provided in the Scope of Services, field visits are to observe the progress and general quality of the work completed by the contractor. Unless expressly stated otherwise, such visits and observation are not intended to be an inspection of the quality or quantity of the Contractor's work but rather are solely intended to allow this office to become generally familiar with the work in progress and to determine, in general, if the work is proceeding in accordance with the Construction Documents directly related to this office's scope of services. During or as a result of these site visits, this office shall neither have control over or charge of, nor be responsible for, the construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the work. Unless required in this Agreement, material testing and inspection shall be provided by a material testing and testing agency retained by others. Section 10: | INDEPENDENT CONTRACTOR Matrix shall be an independent contractor in performing the Services and shall not act as an employee of the CLIENT. As such, and subject to the tems and conditions hereof, Matrix shall be responsible for its employees, subcontractors, and agents and for their compensation, benefits, contributions, and taxes, if any Section 11: JOBSITE HEALTH AND SAFETY Insofar as jobsite safely is concerned, Matrix is responsible solely for its own employees’ and subcontractor's activities on the jobsite, but this shall not be construed to relieve the CLIENT or his contractors from their responsibility for methods of work performance,

or its own employees’ and subcontractor's activities on the jobsite, but this shall not be construed to relieve the CLIENT or his contractors from their responsibility for methods of work performance, superintendence, sequencing of construction, or safety in, on or about the jobsite. Section 12: INSURANCE Matrix is insurance as follows: 1) Worker's Compensation Insurance as required by applicable law, 2) General Liability and Automobile Liability Insurance (in the amount of $1,000,000 combined single limit) for bodily injury and property damage, and 3) Professional Liability (Errors & Omissions) with policy limits equal to at least $1,000,000. Upon request, Matrix shall provide insurance certificates illustrating the coverage herein

MATRIXNEWORLD Engineering Progress CLIENT shall require the contractor(s} hired for the project to maintain general liability insurance (including coverage for premises, personal injury, property damage, completed operations, and contractual liability) naming CLIENT, Matrix and its consultants and employees, as additional insureds. Matrix may terminate services if proof of additional insured status is not provided prior to the start of construction without any liability to CLIENT for resulting damages, whether due to delay or otherwise. Section 13: INDEMNITY A. Matrix Matrix agrees to indemnify and hold harmless CLIENT from and against any damages (including legal fees and costs of investigation where recoverable by law) to the actual extent of negligence of Matrix in the performance of the Services hereunder, provided that such loss, damage, liability or expense is attributable to bodily injury, sickness, disease or death, or to injury to or destruction of tangible property. B. CLIENT The CLIENT, agrees to indemnify and hold harmless Matrix from and against any damages, (including legal fees and costs of investigation where recoverable by law) to the actual extent of negligence of the CLIENT, or anyone directly or indirectly employed by the CLIENT, in the performance of the CLIENT's obligations under the Agreement, any non-conforming wastes waste(s) or discrepancies in the pertinent manifest(s) as defined by applicable regulations, or an condition existing at the work site(s) prior to the date of the Agreement or caused by anyone directly or indirectly employed by the CLIENT. Section 14: LIMIT OF LIABILITY Notwithstanding any other provision contained in the Agreement A. In-no event shall Matrix, its employees, agents, consultants (Including subcontractors) be responsible for any incidental, indirect, impact, or consequential damages (including loss of profits), liabilities or expenses incurred by the CLIENT or any third party as a result of Matrix's Performance or nonperformance of the Services contracted for herein, and the CLIENT waives all such incidental, indirect, impact, or consequential damages. 8. The obligations of Matrix under the Agreement are not intended to and shall not be personally binding on, nor shall any resort be had to the private properties of, any parent, subsidiary or affiliate of Matrix, or any of their respective

greement are not intended to and shall not be personally binding on, nor shall any resort be had to the private properties of, any parent, subsidiary or affiliate of Matrix, or any of their respective officers, directors, shareholders, partners, principals, members, managers, beneficiaries, employees, consultants (including sub-contractors) or agents. Any provision in this Agreement that inures to the benefit of Matrix shall also inure to the benefit of Matrix’s officers, directors, shareholders, partners, principals, members, managers, beneficiaries, employees, consultants (including sub-contractors) or agents. C. —_ Matrix’s total liability to CLIENT for any and all injuries, claims, losses, expenses or damages whatsoever arising out of, or in any way related to the Agreement from any cause or causes, including but not limited to Matrix's errors, negligence, omissions, strict liability, breach of contract or breach of warranty, shall not exceed the total contract amount for the Services provided by Matrix or the limit of liability available at the time of the claim, whichever is lesser. D. Matrix disclaims, and the CLIENT waives, any implied warranties of merchantability or fitness for a particular purpose with respect any equipment or other personal property procured by Matrix and provided to the CLIENT as part of any Services. E. Matrix and CLIENT agree that, to the extent any damages are covered by property insurance during construction, or afterwards, Matrix and CLIENT waive all rights against each other and against the contractors, consultants, agents and employees of the other for damages, except such rights as they may have to the proceeds of such insurance as set forth in the edition of AIA Document A201, General Conditions of the Contract for Construction, current as of the date of this Agreement. Matrix and CLIENT, as appropriate, shall require of the contractors, sub- consultants, agents and employees of any of them similar waivers in favor of the other parties enumerated herein. F, CLIENT recognizes and expects certain Change Orders may be required due, in whole or in part to omissions, ambiguities, or inconsistencies in the Drawings, specifications, and other design documentation furnished by Matrix or as a result of the other professional services performed or furnished by Matrix under this Agreement, and that Matrix is not responsible

ications, and other design documentation furnished by Matrix or as a result of the other professional services performed or furnished by Matrix under this Agreement, and that Matrix is not responsible for the costs associated with these Change Orders to the extent Change Orders include any cost that CLIENT would have incurred if the covered Change Order work had been included originally in the Drawings, specifications, and other design documentation, without any omission, ambiguity, or inconsistency in the Construction Documents. G, To the maximum extent permitted by law, the limitations on damages, the releases from liability, the limitations of liability, and the exclusive remedies provisions expressly provided in the Agreement shall apply even in the event of the fault of Matrix(in whole or in part), including but not limited to negligence , strict liability or breach of contract of Matrix. Section 15: PROJECT DELAYS If Matrix is delayed at any time in performing the Services for any specific project or activity by an act, failure to act, or neglect of the CLIENT or the CLIENT'S employees or any third parties; by changes in the scope of work; by unforeseen circumstances including delays authorized by the CLIENT and agreed to by Matrix; by acts of force majeure including, without limitation, fires, floods, riots, and strikes; by delays caused by foreign or domestic governmental acts or regulations; or by any cause beyond the reasonable control of Matrix, then the time for completion of the Services shall be extended based upon the impact of the delay. Matrix shall receive an adequate compensation adjustment if the delays caused by any of the above result in changes, require additional services, or result in additional costs to Matrix. Section 16: ASSIGNMENT Matrix and CLIENT shall not assign the Agreement in whole or part without the written consent of the other, except that CLIENT may assign this Agreement to an institutional lender providing financing for the Project. In such event, the lender shall assume the CLIENT'S rights and obligations under this Agreement, including full payment of all sums due for services rendered. Matrix shall only execute consents reasonably required to facilitate such assignment, Matrix in no way is prohibited from retaining consultants or subcontractors, or persons and entities not in its employ, when it is

y execute consents reasonably required to facilitate such assignment, Matrix in no way is prohibited from retaining consultants or subcontractors, or persons and entities not in its employ, when it is appropriate to do so. Such persons and entities include, but are not limited to, surveyors, specialized consultants, drilling contractors, and testing laboratories. Matrix's use of others for additional services shall not be unreasonably restricted by the CLIENT provided Matrix notifies the CLIENT in advance. Section 17: THIRD PARTY EXCLUSION Nothing in this Agreement shall be construed to create a cause of action in favor of any third parties, it being the express intent not to create any third- party beneficiaries to this Agreement.

MATRIXNEWORLD Engineering Progress x Section 18: SEVERABILITY if any clause or section of the Agreement shall be deemed void or invalid, such @ decision shall only apply to that particular section(s) and shall not render the rest of the Agreement invalid. The balance of the Agreement shall remain in force. Section 19: | TERMINATION Matrix may terminate the Agreement upon five (6) days’ written notice if the CLIENT defaults in the payment for the Services or for any other material default by the CLIENT under the Agreement. The CLIENT or Matrix may terminate the Agreement upon fourteen (14) days’ written notice for any reason which may arise or for no reason. In the event of such termination of the Agreement for any reason which may arise or for no reason, the termination will become effective fourteen (14) calendar days after receipt of the termination notice. Irrespective of which party shall affect termination of the cause therefore, the CLIENT shall within thirty (30) calendar days of termination remunerate Matrix for the Services rendered and costs incurred (including all reimbursable costs hereunder), in accordance with Matrix's prevailing rate schedule. Section 20: | GOVERNING LAW AND VENUE Unless otherwise provided in an addendum, the law of the State of New Jersey will govern the validity of the Agreement, its interpretation and performance, and remedies for any other claims related to the Agreement. Any litigation arising from this Agreement shall be venued in the Superior Court of New Jersey, Morris County.

ATTACHMENT 2 MATRIX’S FEE SCHEDULE

MATRIXNEWORLD Engineering Progress TITLE HOURLY RATE Expert Professional $350.00 Managing Director III $320.00 Managing Director II $300.00 Technical Director II $300.00 Managing Director | $280.00 Technical Director II $280.00 Technical Director | $260.00 Project Manager IV $245.00 Senior Professional IV $245.00 Project Manager Ill $230.00 Senior Professional Il! $230.00 Project Manager II $215.00 Senior Professional Il $215.00 Project Manager | $195.00 Senior Professional | $195.00 Project Professional IV $185.00 Technical Specialist VIII $185.00 Project Professional II $175.00 Technical Specialist VII $175.00 Project Professional II $165.00 Technical Specialist VI $160.00 Project Professional | $155.00 Technical Specialist V $150.00 Staff Professional IV $145.00 Staff Professional III $135.00 Technical Specialist IV $135.00 Technical Specialist Ill $125.00 Staff Professional Il $120.00 Technical Specialist II $115.00 Staff Professional | $110.00 Technical Specialist | $105.00 Administrative Support Il $80.00 Administrative Support | $70.00 ITEM FEE Black & White Copy 8% x 11 to 18 x 24 $0.25/sheet Black & White Copy 24 x 36 to 30 x 42 $3.25/sheet Color Copy 8% x 11 to 11x17 $0.50/sheet Color Copy 24 x 36 to 30 x 42 $35.00/sheet Mylar 24 x 36 $40.00/sheet Mylar 30 x 42 $60.00/sheet Robotic per diem $350.00 Scanner per diem $475.00 Subconsultants 115% of cost Out-of-pocket expenses 115% of cost Mileage expenses Federal rates