263-22 Proposal - SCE.pdf

SCE-P13155.011 August 22, 2022 expenses, including attorneys' fees, arising out of such reuse by Client or by others acting through Client. Indemnification To the fullest extent permitted by law, Client and SCE each agree to indemnify the other party and the other party's officers, directors, partners, employees and representatives, from and against losses, damages and judgments arising from claims by third parties, including reasonable attorneys’ fees and expenses recoverable under applicable law, but only to the extent they are found to be caused by a negligent act, error or omission of the indemnifying party or any of the indemnifying party's officers, directors, members, partners, agents, employees or sub-consultants in the performance of services under this Agreement. If claims, losses, damages and judgments are found to be caused by the joint or concurrent negligence of Client and SCE, they shall be borne by each party in proportion to its negligence. Force Majeure Neither party shall be deemed in default of this agreement to the extent that any delay or failure in the performance of its obligations results from any cause beyond its reasonable control and without its negligence. Dispute Resolution Client and SCE agree that they shall first submit any and all unsettled claims, counterclaims, disputes and other matters in question between them arising out of or relating to the agreement to mediation in accordance with the Consiruction Industry Mediation Rules of the American Arbitration Association, effective as of the date of this agreement. Use of Electronic Media Documents that may be relied upon by Client are limited to those that are signed or sealed by SCE. Unsigned files in electronic media format or text, data, graphic or other types that are furnished by SCE to Client are only for convenience of Client. Any conclusion or information obtained or derived from such electronic files will be at the user's sole risk. When transferring documents in electronic media format, SCE makes no representations as to long-term compatibility, usability or readability of documents resulting from the use of software application packages, operating systems or computer hardware differing from those in use by SCE at the beginning of this assignment. Construction Phase Services If this Agreement provides for any construction phase services by SCE, it is

or computer hardware differing from those in use by SCE at the beginning of this assignment. Construction Phase Services If this Agreement provides for any construction phase services by SCE, it is understood that the Contractor, not SCE, is responsible for the construction of the project, and that SCE is not responsible for the acts or omissions of any contractor, subcontractor or material supplier; for safety precautions, programs or enforcement; or for construction means, methods, techniques, sequences and procedures employed by the Contractor. It is the Owner's responsibility fo advise their contractor of these terms.