188-25 Exhibit B_Executed Agreement-TAP_NJDOT_WO.pdf

available to it. Therefore, the Client agrees, to the fullest extent permitted by law, to hold harmless and release MFS from and against all damages, liabilities, or costs, including reasonable attorneys’ fees and defense costs, arising out of or in any way connected with the Client's decision not to expend additional sums to further investigate existing conditions on this project, excepting only those damages, liabilities, or costs attributable to the sole negligence and/or willful misconduct of MFS. Further, MFS shall have the right to rely on the accuracy and completeness of all information furnished to it by the Client. MFS shal! not be responsible for interpretations by others of the information it develops or provides to the Client. 4, INVOICING, SERVICE CHARGES Invoices are payable within 30 days of receipt. A service charge of 2% per month will be imposed on all bills not paid within 30 days. The Client shall have no right of setoff against the amounts due to MFS and no deductions shall be made from MFS's compensation on account of any actual or alleged claim, action, breach, error, omission, tort, fault, wrong, liability, penalty, or damage actually or allegedly coused by, arising from, or relating to MFS, MFS's services on the Project, or this Agreement in the event of a suspension of services or termination of the Agreement by MFS either due to non-payment of invoices, and/or in accordance with Paragraph 5, Termination, of these Terms and Conditions, MFS shall have no liability for any delay or damage of any kind actually or allegedly caused by such suspension of services or termination. Before resuming services, MFS shall be paid all sums due prior to suspension and any expenses incurred in the interruption and resumption of MFS's services. MFS's fees for the remaining services and the time schedules shall be equitably adjusted. In the event the Client foils to pay MFS on account of services rendered as set forth on an MFS invoice, the Client agrees that it is responsible for all reasonable costs of collection, including attorneys’ fee and staff time spent on depositions and court appearances, incurred by MFS in connection with its collection efforts against the Client. 5. TERMINATION Except as otherwise provided in this Agreement, this Agreement may be terminated by either party upon not less than seven (7) calendar days’ written notice,

fforts against the Client. 5. TERMINATION Except as otherwise provided in this Agreement, this Agreement may be terminated by either party upon not less than seven (7) calendar days’ written notice, should the other party fail substantially to perform in accordance with the terms and conditions of this Agreement through no fault of the party initiating the termination. If the defaulting party fails to cure its default within the seven (7) calendar day notice period or fails to commence action to cure its default if the cure cannot reasonably be completed within the seven (7) days, the non-defaulting party may terminate the Agreement. Failure of the Client to make payments to MFS in accordance with this Agreement shall be considered substantial non-performance and grounds for termination or suspension of services at MFS's option, regardless of any alleged fault attributable to MFS, and no seven (7) day notice period is required. In the event of termination, MFS shall be compensated for all services performed and reimbursable expenses incurred prior to such termination, all termination expenses, and anticipated profit in connection with project under this Agreement. 6. DISPOSAL OF SAMPLES All samples, contaminated or otherwise (‘Samples’), collected by MFS while performing services under this Agreement are the property and responsibility of the Client. Upon written notice, MFS may dispose of Samples in its possession after ninety (90) calendar days unless otherwise required by law or other arrangements are mutually agreed to in writing by the parties. The Client shall be responsible for all costs incurred in connection with the disposal of Samples. At all times, any and all rights, title, and responsibility for Samples shall remain with the Client and under no circumstances shall these rights, title, and responsibility be transferred to MFS. 7. JOBSITE SAFETY AND CONTROL OF WORK MES shall take reasonable precautions to safeguard its own employees. Except as otherwise expressly agreed to in writing by MFS, MFS shall have no responsibility for the safety program at the Project nor the safety of any contractor or subcontractor or construction manager of the Client or other person. Neither the professional activities of MFS nor the presence of MFS's employees and subcontractors at the Project site shall be construed to confer upon MFS any responsibility for

ient or other person. Neither the professional activities of MFS nor the presence of MFS's employees and subcontractors at the Project site shall be construed to confer upon MFS any responsibility for any activities on site performed by personnel other than MFS's employees. The Client agrees that MFS shall have no power, authority, right, or obligation to supervise, direct, stop the work of, or control the activities of any contractors or subcontractors or construction manager of the Client, their agents, servants, or employees. 8. INDEMNIFICATION Subject to the provisions of Paragraph 9, Limitation of Liability, of this Agreement, MFS agrees to indemnify and hold the Client and the Client's parents, subsidiaries, affiliates, partners, officers, directors, shareholders, employees, and agents harmless for any and all claims, damage obligations, liabilities, suits, demands, and losses for personal injury and/or property damage, including reasonable attorney's fees and other expenses where recoverable by law, asserted by any third parties, but only to the extent of MFS's negligence in the performance of its services under this Agreement In no event shall MFS be responsible for any loss, damage, or liability arising from or caused by any acts of the Client or third party or any of their agents, employees, staff, or other consultants, subconsultants, contractors, or subcontractors. In no event shall the indemnification obligation extend beyond the date when the institution of legal or equitable proceedings for professional negligence would be barred by an applicable statute of repose or statute of limitations. 9. LIMITATION OF LIABILITY The Client agrees to limit MFS's liability to the Client and to any and all of the Client's parents, subsidiaries, affiliates, partners, officers, directors, shareholders, employees, agents, construction managers, contractors, subcontractors, consultants, subconsultants, and insurers for any and all damages arising out of or relating to the performance of MFS's services under this Agreement, such that MFS's aggregate liability to all those named will not exceed the lesser of (i) five times MFS's fee for its services on the Project or (ii) MFS's available professional liability insurance coverage at the time of any settlement or judgment. In the event that any portion of this limitation of liability provision is

s on the Project or (ii) MFS's available professional liability insurance coverage at the time of any settlement or judgment. In the event that any portion of this limitation of liability provision is deemed unenforceable or void as a matter of law, then MFS's liability pursuant to this Paragraph 9, Limitation of Liability, shall be limited to the lowest amount ollowable as a matter of law. The Client agrees to notify any of its construction managers, contractors, subcontractors, consultants, subconsultants, and insurers who may perform work on behalf of the Client in connection with this Agreement of such limitation of professional liability for defects, errors, omissions, or negligence and to require as a condition precedent to their performing their work a like indemnity and limitation of liability on their part in favor of MFS. To the fullest extent permitted by law, the Client further agrees that no shareholder, officer, director, partner, principal, or employee of MFS shall have personal liability for any act, omission, breach, tort, fault, or wrong arising from or relating to MFS's services on the Project or under this Agreement The Client waives consequential damages, including, but not limited to, loss of use or loss of profits for claims, disputes, or other matters in Initials: Date: Page 2 of &