244-25 Combine Consultants RFPs_compressed.pdf

SCE-P14706.011 October 9, 2025 resulting from the use of software application packages, operating systems, or computer hardware differing from those in use by SCE at the beginning of this assignment. Estimated Fee(s) Any estimated fee(s) provided above, is/are based on several assumptions for the scope of services provided in this proposal relative to project unknowns. If it is determined that there is a significant change of conditions that was not anticipated, SCE will notify the Client prior to exceeding the contract amount to address the changes associated with the project and to establish an acceptable course of action needed to complete the scope of services. Bid Phase Services If this Agreement provides for any bid phase services by SCE, it is understood that any bid phase services described herein are associated with one (1) contract and one (1) bid period. Should the Client direct the project to be bid and constructed under multiple contracts or should the bid process fail to result in a successful contract award requiring the need to rebid the project, SCE’s services associated with multiple contracts or rebidding any contract (original or revised) will be offered under a contract amendment to SCE’s scope of services. Additionally, it is assumed that Bid Phase Services will commence upon conclusion of final design/contract document preparation, with no significant project delays. Significant project delays may result in a fee adjustment to our services. Construction Phase Services If this Agreement provides any construction phase services by SCE, it is understood that the Contractor, not SCE, is responsible for the construction and schedule adherence of the project, and that SCE is not responsible for the acts or omissions of any Contractor, subcontractor, or material supplier; for safety precautions, programs, or enforcement; or for construction means, methods, techniques, sequences, and procedures employed by the Contractor. It is the Owner’s responsibility to advise their Contractor of these terms. Additionally, it is assumed that Construction Phase Services will commence upon conclusion of the Bid Phase services, with no significant project delays. Significant project delays may result in a fee adjustment to our services. Opinions of Cost When included in SCE's Scope of Services, opinions or estimates of probable construction cost are prepared

. Significant project delays may result in a fee adjustment to our services. Opinions of Cost When included in SCE's Scope of Services, opinions or estimates of probable construction cost are prepared on the basis of SCE's experience and qualifications and represent SCE's judgment as a professional generally familiar with the industry. However, since SCE has no control over the cost of labor, materials, equipment, or services furnished by others, over Contractor's methods of determining prices, or over competitive bidding or market conditions, SCE cannot and does not guarantee that proposals, bids, or actual construction cost will not vary from SCE's opinions or estimates of probable construction cost. Professional Responsibility SCE represents that the services shall be performed, within the limits prescribed by Client, in a manner consistent with the level of care and skill ordinarily exercised by other professional consultants under similar circumstances. No other representation to Client, 10